재해위험 개선사업 및 이주대책에 관한 특별법 시행령 제28조(선수금)
Enforcement Decree of the Special Act on Disaster Risk Improvement Projects and Relocation Measures, Article 28 (Advance Payments)
① 법 제20조에 따라 개선사업으로 조성된 토지ㆍ건축물 또는 공작물 등을 공급받거나 이용하려는 자로부터 선수금을 받으려는 사업시행자는 다음 각 호의 요건을 모두 갖추어 행정안전부장관 또는 시ㆍ도지사의 승인을 받아야 한다. <개정 2014.11.19, 2017.7.26>
(1) A project implementer who intends to receive advance payments from persons who intend to be supplied with or use land, buildings or structures, etc. created by an improvement project under Article 20 of the Act shall meet all of the following requirements and obtain approval of the Minister of the Interior and Safety or the Mayor/Do Governor:
1. 시행계획 승인을 받을 것
1. Approval of the implementation plan has been obtained;
2. 개선사업지구 토지면적 중 50퍼센트 이상 토지의 소유권을 확보하고 개선사업에 착수할 것
2. Ownership of at least 50 percent of the land area of the improvement project district has been secured and the improvement project has commenced;
3. 공급하려는 토지ㆍ건축물 또는 공작물의 소유권을 확보하고 그 토지에 설정된 저당권을 말소하였을 것
3. Ownership of the land, buildings or structures to be supplied has been secured and mortgages established on the land have been cancelled;
4. 공급하려는 토지에 대한 개선사업 공사진척률이 10퍼센트 이상일 것
4. The construction progress rate of the improvement project for the land to be supplied is at least 10 percent;
5. 관할 시장ㆍ군수로부터 법 제4조제2항에 따른 협의서에 따라 사업장의 설치 및 이전이 정상적으로 추진되고 있음을 확인받을 것
5. Confirmation has been obtained from the competent head of a Si/Gun that the installation and relocation of workplaces are being properly promoted according to the consultation document under Article 4 (2) of the Act;
6. 공급계약 불이행 시 선수금의 환불을 담보하기 위하여 다음 각 목의 내용이 포함된 「국가를 당사자로 하는 계약에 관한 법률 시행령」 제37조제2항에 따른 지급보증서ㆍ유가증권ㆍ보증보험증권ㆍ정기예금증서ㆍ수익증권 등의 보증서(이하 "보증서등"이라 한다. 이 조에서 같다)를 행정안전부장관 또는 시ㆍ도지사에게 제출할 것. 다만, 나목의 경우 그 사업기간을 연장할 때에는 원래의 보증 또는 보험의 기간에 그 연장하려는 기간을 더한 기간을 보증 또는 보험 기간으로 하는 보증서등을 제출하여야 한다.
6. To secure the refund of advance payments in case of non-performance of the supply contract, a guarantee certificate, such as a payment guarantee, securities, surety insurance policy, time deposit certificate or beneficiary certificate under Article 37 (2) of the Enforcement Decree of the Act on Contracts to Which the State Is a Party (hereinafter referred to as a "guarantee certificate, etc."; the same applies in this Article) containing the following shall be submitted to the Minister of the Interior and Safety or the Mayor/Do Governor. However, in the case of item (b), when extending the project period, a guarantee certificate, etc. covering a guarantee or insurance period obtained by adding the extension period to the original guarantee or insurance period shall be submitted:
가. 보증 또는 보험의 금액은 선수금에 보증 또는 보험 기간에 해당하는 약정이자 상당액을 더한 금액 이상으로 할 것
(a) The guaranteed or insured amount shall be at least the advance payment plus the amount equivalent to the agreed interest for the guarantee or insurance period;
나. 보증 또는 보험 기간의 개시일은 선수금을 받은 날 이전이어야 하며, 그 종료일은 준공예정일 이후로 하되, 보증 또는 보험의 종료일은 준공예정일부터 1개월 이상의 차이를 둘 것
(b) The start date of the guarantee or insurance period shall be on or before the date the advance payment is received, and the end date shall be after the scheduled completion date, with the end date of the guarantee or insurance differing from the scheduled completion date by at least one month.
② 제1항에 따라 사업시행자가 공사완료의 공고 전에 미리 토지ㆍ건축물 또는 공작물을 공급하거나 이용하게 한 후에는 그 토지 등을 담보로 제공하여서는 아니 된다.
(2) After a project implementer has, under paragraph (1), supplied or allowed the use of land, buildings or structures in advance before the announcement of completion of construction, the project implementer shall not provide such land, etc. as security.
③ 행정안전부장관 또는 시ㆍ도지사는 사업시행자가 공급계약을 이행하지 아니하거나 사업시행자의 파산 등(「채무자 회생 및 파산에 관한 법률」에 따른 법원의 결정ㆍ인가를 포함한다)으로 사업을 이행할 능력이 없다고 인정하는 경우에는 해당 개선사업의 준공 전에 보증서등을 선수금의 환불을 위하여 사용할 수 있다. <개정 2014.11.19, 2017.7.26>
(3) Where the project implementer does not perform the supply contract, or the Minister of the Interior and Safety or the Mayor/Do Governor recognizes that the project implementer is unable to perform the project due to bankruptcy, etc. (including a court decision or authorization under the Debtor Rehabilitation and Bankruptcy Act), the guarantee certificate, etc. may be used to refund the advance payments before completion of the relevant improvement project.
영어는 이 사이트가 원문에서 옮긴 비공식 번역으로, 영어 공부를 돕기 위한 것입니다. 법적 효력은 한국어 원문에만 있습니다. 낱말 위 한글은 소리 나는 대로 적은 발음이며 굵은 글자가 강세입니다.
시행 2025.10.1 · 대통령령 · 행정안전부 소관